Thomas & Associates, Inc., v. The Metropolitan Government of Nashville and Davidson County, et al.

This appeal involves a dispute between a road contractor and the Tennessee Department of Transportation involving two construction projects in the Nashville area. Following extensive construction delays attributed to the relocation of utilities, the contractor filed claims based on negligence and breach of contract with the Tennessee Division of Claims Administration which were transferred to the Circuit Court for Davidson County. The trial court granted the Department's motion for summary judgment and dismissed all the contractor's claims. We have determined that the trial court correctly dismissed the contractor's negligence claims but that the trial court erred by denying the contractor's breach of contract claims. Accordingly, we vacate the portion of the judgment dismissing the contractor's contract claims and remand the case for further proceedings.